____________________________
EMPLOYMENT
____________________________
SEEKING TRAVEL NURSES
Medical – Travel nurses to Tuscaloosa. RNs and LPNs needed for psych, medical, & LTC units. All shifts, full benefits. Call Carson at Worldwide Staffing at 866-633-3700, ext. 123 or email CGaughan@WorldWideTravelStaffing.com
BT3/12/2026
______________________________
COMMISSIONING ENGINEER II
Commissioning Engineer II, Sain Engineering Associates, Inc, Birmingham, Al. Design & submittal review for commercial/industrial HVAC & Elect systems such as Air Handling Units, Var Air Volume, Chiller Plants, Condenser Water Plants, Boiler Plants, Auto Trf Switches, Generators, & Lighting Controls. Reqs Bach in Mechanical / Electrical Eng from ABET accredited university +1 yr of exp which can include academic co-op commissioning prog. 10-15% US travel to client sites for eval & testing. Email resume to careers@saineng.com & include job title in subject line.
BT3/19/2026
______________________________
______________________________
LEGAL
______________________________
01-CV-25-904391
NOTICE OF FINAL HEARING BY PUBLICATION
TO: ISAIAH L. CRAIG, JR.; TUTOR U. ORAWANL STRATEGIC MUNICIPAL INVESTMENTS, LLC; J.T. SMALLWOOD; JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title , estate, lie, or interest in the real estate described herein,
TAKE NOTICE that on October 10, 2025, the Birmingham Land Bank Authority file the above-styled Complaint, and the Land Bank asserts that it has recorded notice of a pending quiet title and foreclosure action in the Probate Court of Jefferson County, Alabama concerning the rights and/or interests in the following real property:
That parcel of real property located at 2921 Avenue Z, Birmingham, Alabama 35208 and having legal description of:
Lot 15, in Block 5 according to the Survey of Fairview Park, as recorded in Map Book 5 Page 115, in the Office of the Judge of Probate in Jefferson County, Alabama; A/K/A LOT 15 BLK 5 FAIRVIEW PARK.
(It appears said legal is the same as the certain legal described in Instrument No. (No Instrument Number Listed) as follows: Lot 15, BLK 5 FAIRVIEW PARK) and known as Parcel ID No. 12-90-00-551-023-008-000.000; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien, or interested in the rea estate described herein, Defendant.
Tax Parcel ID No. 12-90-00-51-023-008-000.000
ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESTULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The final hearing on this quiet title and foreclosure action is hereby set for April 13,2026, in Court Room 360, Jefferson County Courthouse in Birmingham, Alabama at 10:00 A.M. The judgement of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 40-10-73 (1975) et. Seq or Alabama Code 40-10-83 (1975) et, seq. may redeem the property pursuant to those statues within five (5) days after the appropriate Order on Final Hearing is issued. FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPETION TO THE CIRICUT COURT WITHIN THE 5-DAY PERIOD MAY RESULT IN A LOSS OF RIGHT OF REDEMPTION.
The address of the Birmingham Land Bank Authority is City Hall, 710 North 20th Street, Birmingham, AL 35203. The Birmingham Land Bank Authority may be contacted care if Greer B Mallet, Christian & Small, LLP, 505 20th Street North, suite 1800 Financial Center, Birmingham AL 35203 at (205) 795-6588.
IT IS THEREOFRE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in the Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above-described land or any part thereof are hereby directed to plead, answer or otherwise to the Complaint in this cause before the hearing date or a judgement by default may be rendered against them it being intended this notice shall be used to perfect service against all parties who cannot be personally served with a copy of the Complaint.
BT3/19/2026
______________________________
01-CV-2025-904395.00
NOTICE OF FINAL HEARING BY PUBLICATION
TO: JEANETTA RAKESTRAW MORRIS JONES; TLR AL, LLCL AMERIQUEST MORTGAGE COMPANY; J.T. SMALLWOOD; JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title , estate, lie, or interest in the real estate described herein,
TAKE NOTICE that on October 10, 2025, the Birmingham Land Bank Authority file the above-styled Complaint, and the Land Bank asserts that it has recorded notice of a pending quiet title and foreclosure action in the Probate Court of Jefferson County, Alabama concerning the rights and/or interests in the following real property:
That parcel of real property located at 6801 6th Avenue South, Birmingham, Alabama 35212 and having legal description of:
Lot 13, in Block 1 according to the map of Dromgoole’s Addition to Gate City, as recorded in Map Book 3 Page 5, in the Office of the Judge of Probate in Jefferson County, Alabama; A/K/A LOT 13 BLK 1 BROMGOOLES SUR.
(It appears said legal is the same as the certain legal described in Instrument No. (No Instrument Number Listed) as follows: Lot 13, BLK 1 BROMGOOLES SUR) and known as Parcel ID No. 01-23-00-22-301-700-300.000; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien, or interested in the rea estate described herein, Defendant.
Tax Parcel ID No. 01-23-00-22-301-700-300.000
ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESTULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The final hearing on this quiet title and foreclosure action is hereby set for April 13,2026, in Court Room 360, Jefferson County Courthouse in Birmingham, Alabama at 10:00 A.M. The judgement of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 40-10-73 (1975) et. Seq or Alabama Code 40-10-83 (1975) et, seq. may redeem the property pursuant to those statues within five (5) days after the appropriate Order on Final Hearing is issued. FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPETION TO THE CIRICUT COURT WITHIN THE 5-DAY PERIOD MAY RESULT IN A LOSS OF RIGHT OF REDEMPTION.
The address of the Birmingham Land Bank Authority is City Hall, 710 North 20th Street, Birmingham, AL 35203. The Birmingham Land Bank Authority may be contacted care if Greer B Mallet, Christian & Small, LLP, 505 20th Street North, suite 1800 Financial Center, Birmingham AL 35203 at (205) 795-6588.
IT IS THEREOFRE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in the Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above-described land or any part thereof are hereby directed to plead, answer or otherwise to the Complaint in this cause before the hearing date or a judgement by default may be rendered against them it being intended this notice shall be used to perfect service against all parties who cannot be personally served with a copy of the Complaint.
BT3/19/2026
______________________________
01-CV-2025-904392.00
NOTICE OF FINAL HEARING BY PUBLICATION
TO: ANGELA MARTIN; CAROLYN MARTIN; EMMA MARTIN, deceased, and her unknown heirs, successors, and assign; J.T. SMALLWOOD; JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title , estate, lie, or interest in the real estate described herein,
TAKE NOTICE that on October 10, 2025, the Birmingham Land Bank Authority file the above-styled Complaint, and the Land Bank asserts that it has recorded notice of a pending quiet title and foreclosure action in the Probate Court of Jefferson County, Alabama concerning the rights and/or interests in the following real property:
That parcel of real property located at 1608 4th ST N, Birmingham, Alabama 35204 and having legal description of:
Lot 4 and 5, in Block 4 according to the Survey of Tarran and McMillan Addition to Birmingham, as recorded in Map Book 3 Page 60, in the Office of the Judge of Probate in Jefferson County, Alabama.
Tax Parcel ID No. 22-00-26-2-028-008.000
ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESTULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The final hearing on this quiet title and foreclosure action is hereby set for April 14, 2026, in Court Room 360, Jefferson County Courthouse in Birmingham, Alabama at 9:00 A.M. The judgement of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 40-10-73 (1975) et. Seq or Alabama Code 40-10-83 (1975) et, seq. may redeem the property pursuant to those statues within five (5) days after the appropriate Order on Final Hearing is issued. FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPETION TO THE CIRICUT COURT WITHIN THE 5-DAY PERIOD MAY RESULT IN A LOSS OF RIGHT OF REDEMPTION.
The address of the Birmingham Land Bank Authority is City Hall, 710 North 20th Street, Birmingham, AL 35203. The Birmingham Land Bank Authority may be contacted care if Greer B Mallet, Christian & Small, LLP, 505 20th Street North, suite 1800 Financial Center, Birmingham AL 35203 at (205) 795-6588.
IT IS THEREOFRE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in the Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above-described land or any part thereof are hereby directed to plead, answer or otherwise to the Complaint in this cause before the hearing date or a judgement by default may be rendered against them it being intended this notice shall be used to perfect service against all parties who cannot be personally served with a copy of the Complaint.
BT3/19/2026
______________________________
01-CV-2025-904419.00
NOTICE OF FINAL HEARING BY PUBLICATION
TO: WILLIAM JAMES PARKS; GRACIE A MARTIN-PARKS; DIANNE LEWIS BARNEY; JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title , estate, lie, or interest in the real estate described herein,
TAKE NOTICE that on October 10, 2025, the Birmingham Land Bank Authority file the above-styled Complaint, and the Land Bank asserts that it has recorded notice of a pending quiet title and foreclosure action in the Probate Court of Jefferson County, Alabama concerning the rights and/or interests in the following real property:
That parcel of real property located at 945 47th Place North, Birmingham, Alabama 35212 and having legal description of:
Lot 7, in Block 2 according to the Survey of J.L. Bivings Addition, as recorded in Map Book 11 Page 90, in the Office of the Judge of Probate in Jefferson County, Alabama; A/K/A LOT 7 BLK 2 F L BIVINGS ADD.
(It appears said legal is the same as the certain legal described in Instrument No. (No Instrument Number Listed) as follows: Lot 7, BLK 2 F L BIVINGS ADD) and known as Parcel ID No. 01-23-00-20-10-270-013.000; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien, or interested in the rea estate described herein, Defendant.
Tax Parcel ID No. 01-23-00-20-10-270-013.000
ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESTULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The final hearing on this quiet title and foreclosure action is hereby set for April 13,2026, in Court Room 360, Jefferson County Courthouse in Birmingham, Alabama at 10:00 A.M. The judgement of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 40-10-73 (1975) et. Seq or Alabama Code 40-10-83 (1975) et, seq. may redeem the property pursuant to those statues within five (5) days after the appropriate Order on Final Hearing is issued. FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPETION TO THE CIRICUT COURT WITHIN THE 5-DAY PERIOD MAY RESULT IN A LOSS OF RIGHT OF REDEMPTION.
The address of the Birmingham Land Bank Authority is City Hall, 710 North 20th Street, Birmingham, AL 35203. The Birmingham Land Bank Authority may be contacted care if Greer B Mallet, Christian & Small, LLP, 505 20th Street North, suite 1800 Financial Center, Birmingham AL 35203 at (205) 795-6588.
IT IS THEREOFRE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in the Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above-described land or any part thereof are hereby directed to plead, answer or otherwise to the Complaint in this cause before the hearing date or a judgement by default may be rendered against them it being intended this notice shall be used to perfect service against all parties who cannot be personally served with a copy of the Complaint.
BT3/19/2026
______________________________
01-CV-2025-904420
NOTICE OF FINAL HEARING BY PUBLICATION
TO: NONIDEZ PROPERTIES, a General Partnership; WILLIAM K. NONIDEZ; THE UNKNOWN HEIRS OF JOSE FERNANDEZ NONIDEZ, III, deceased; JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title , estate, lie, or interest in the real estate described herein,
TAKE NOTICE that on October 14, 2025, the Birmingham Land Bank Authority file the above-styled Complaint, and the Land Bank asserts that it has recorded notice of a pending quiet title and foreclosure action in the Probate Court of Jefferson County, Alabama concerning the rights and/or interests in the following real property:
That parcel of real property located at 1756 13th CT S, Birmingham, Alabama 35205 and having legal description of:
The West 15 feet of Lot 24 according to Malone and Smyers Subdivision of part of Block 779, Birmingham, as recorded in Map Book 5 Page 39, in the Office of the Judge of Probate in Jefferson County, Alabama, and assigned
Parcel ID No. 29-00-01-4-003-019.000
ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESTULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The final hearing on this quiet title and foreclosure action is hereby set for April 14,2026, in Court Room 360, Jefferson County Courthouse in Birmingham, Alabama at 9:00 A.M. The judgement of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 40-10-73 (1975) et. Seq or Alabama Code 40-10-83 (1975) et, seq. may redeem the property pursuant to those statues within five (5) days after the appropriate Order on Final Hearing is issued. FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPETION TO THE CIRICUT COURT WITHIN THE 5-DAY PERIOD MAY RESULT IN A LOSS OF RIGHT OF REDEMPTION.
The address of the Birmingham Land Bank Authority is City Hall, 710 North 20th Street, Birmingham, AL 35203. The Birmingham Land Bank Authority may be contacted care if Greer B Mallet, Christian & Small, LLP, 505 20th Street North, suite 1800 Financial Center, Birmingham AL 35203 at (205) 795-6588.
IT IS THEREOFRE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in the Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above-described land or any part thereof are hereby directed to plead, answer or otherwise to the Complaint in this cause before the hearing date or a judgement by default may be rendered against them it being intended this notice shall be used to perfect service against all parties who cannot be personally served with a copy of the Complaint.
BT3/19/2026
______________________________
01-CV-2025-904422
NOTICE OF FINAL HEARING BY PUBLICATION
TO: GRACE PERRY JONES; BANKERS TRUST COMPANY, as TRUSTEE; ERCO CREDIT UNION; JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title , estate, lie, or interest in the real estate described herein,
TAKE NOTICE that on October 14, 2025, the Birmingham Land Bank Authority file the above-styled Complaint, and the Land Bank asserts that it has recorded notice of a pending quiet title and foreclosure action in the Probate Court of Jefferson County, Alabama concerning the rights and/or interests in the following real property:
That parcel of real property located at 702 Delta Street, Birmingham, Alabama 35205 and having legal description of:
South 24 feet of Lot 35, and the North 2 feet of Lot 34, in Block 2 according to the Survey of Tiddlesville Heights, as recorded in Map Book 8 Page 81, in the Office of the Judge of Probate in Jefferson County, Alabama; A/K/A S 24 FT OF LOT 35 & n 2 FT OF LOT 34 BLK 2 TIDDLESVILLE HGTS HEIGHTS.
(It appears said legal is the same as the certain legal described in Instrument No. (No Instrument Number Listed) as follows: S 24 FT OF LOT 35 & N 2 FT OF LOT 34 BLK 2 TIDDLESVILLE HGTS HEIGHTS) and known as Parcel ID No. 01-29-00-02-303-104-600.000; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien, or interested in the rea estate described herein, Defendant.
Tax Parcel ID No. 01-2-00-02-303-104-600.000
ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESTULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The final hearing on this quiet title and foreclosure action is hereby set for May 11, 2026, in Court Room 360, Jefferson County Courthouse in Birmingham, Alabama at 10:00 A.M. The judgement of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 40-10-73 (1975) et. Seq or Alabama Code 40-10-83 (1975) et, seq. may redeem the property pursuant to those statues within five (5) days after the appropriate Order on Final Hearing is issued. FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPETION TO THE CIRICUT COURT WITHIN THE 5-DAY PERIOD MAY RESULT IN A LOSS OF RIGHT OF REDEMPTION.
The address of the Birmingham Land Bank Authority is City Hall, 710 North 20th Street, Birmingham, AL 35203. The Birmingham Land Bank Authority may be contacted care if Greer B Mallet, Christian & Small, LLP, 505 20th Street North, suite 1800 Financial Center, Birmingham AL 35203 at (205) 795-6588.
IT IS THEREOFRE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in the Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above-described land or any part thereof are hereby directed to plead, answer or otherwise to the Complaint in this cause before the hearing date or a judgement by default may be rendered against them it being intended this notice shall be used to perfect service against all parties who cannot be personally served with a copy of the Complaint.
BT3/19/2026
______________________________
ADVERTISEMENT FOR BID
Sealed proposals will be received from pre-qualified bidders by Ms. Jenna Morgan on behalf of Dr. Christopher B. Roberts, President of Auburn University at 1161 West Samford Avenue, Auburn University, AL 36849 until 3:00 PM Central Time, April 9, 2026 for:
22-399 – Harris Early Learning Ctr – Playground Repairs
AUBURN UNIVERSITY
at which time and place they will be publicly opened and read in Facilities Management Building One, Training Room A
SCOPE OF WORK:
The general scope of the work includes but is not limited to:
The project entails the renovation of the courtyard playgrounds at the Harris Early Learning Center in Birmingham, Alabama. The scope includes replacement of playground surfacing, repair, and painting of concrete pathways, flushing of storm water drains and upgrading of drain grates, enhancements to an existing wood play structure, as well as additional general improvements to the playground areas.
The Pre-Bid Conference will be held on March 26, 2026 at 11:30 A.M. CST at Harris Early Learning Center, Main Lobby, 1413 7th Avenue North, Birmingham, AL 35203.
In accordance with Code of Alabama, 39-2-2(a), prequalification is required for this project. The prequalification application is available on the Auburn University Public Works Bid Calendar located at: https://fm.auburn.edu/bid-calendar/.
For all questions or inquiries about this project, please contact:
Whitney Brock, whitneybrock@auburn.edu; 334-752-1301
DOCUMENTS:
Drawings may be examined at the following locations:
Drawings and specifications may be examined at the Office of the Owner: Planning, Design & Construction, Facilities Management, Auburn University, AL. See link below.
Auburn University Facilities Management Website:
https://fm.auburn.edu/contractor/
BONDS:
A certified check or bid bond payable to Auburn University in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00, must accompany the bidder’s proposal. Performance and Statutory Labor and Material Payment Bonds will be required at the signing of the Contract.
BIDS:
Bids must be submitted on proposal forms or copies thereof furnished by the Architect.
Dr. Christopher B. Roberts, President
Auburn University
Auburn University, AL 36849
BT3/19/2026
__________________________________
INVITATION TO BID
ITB# 27-26 “CRANE & HOIST MAINTENANCE AND INSPECTIONS”
JEFFERSON COUNTY, AL
Bids will be received by the Jefferson County Commission Purchasing Agent Michael D. Matthews, Ph.D., C.P.M., until 4:00 (CST) p.m. on Tuesday, April 7, 2026, for ITB 27-26 CRANE & HOIST MAINTENANCE AND INSPECTIONS. All solicitation information including forms, and specifications are available for download free at https://jeffcobids.jccal.org/Search.aspx. Interested parties must meet bidder requirements and qualifications as specified in the bid documents on or before the date that the bids are due. All questions must be submitted in writing to procurementservices@jccal.org attention Charles Lindsey/ DoMonique Andrews. A mandatory site visit will be held Tuesday, March 24, 2026 at 10:00 a.m. (CST) AT ESD Village Creek 1440 Please Hill Rd. Birmingham AL. Pre Bid Conference will be Held March 25, 2026 at 10 a.m. (CST) in Purchasing Suite 830 of the Jefferson County Main Courthouse, 716 Richard Arrington, Jr. Blvd. N., Birmingham, AL 35203.
BT3/19/2026
_________________________________
BID 26-12-04 NOTICE TO BIDDERS
Central Alabama will be accepting sealed bids for Underground Utility Line Locating Services, BID 26-12-04. The specifications may be examined and obtained in the Purchasing Department’s office at 3600 First Avenue North, Birmingham, AL 35222, or by emailing derleda.abrom@caw-al.gov, or our website at www.caw-al.gov. Sealed bids for Underground Utility Line Locating Services will be received in the Purchasing Department not later than Tuesday, March 24, 2026, at which time and place they will be publicly opened and read. The pre-bid conference will be held at the Central Alabama Main Complex on Monday, March 9, 2026, at 3:00 p.m. Please RSVP by Friday, March 6, 2026, 4:30 p.m. Prospective bidders should deliver or mail their sealed bids to 3600 1st Avenue North, Birmingham, Alabama 35222, directed to the attention of LyTonja Levert, Purchasing Manager, and marked in the lower left-hand corner of the envelope as follows: “Underground Utility Line Locating Services, BID26-12-04, Tuesday, March 24, 2026, at 10:00 a.m.”
BT3/19/2026
_________________________________
SECTION 006519 ADVERTISEMENT FOR COMPLETION
LEGAL NOTICE
IN ACCORDANCE WITH SECTION 39-1 AS AMENDED BY H275 CODE OF ALABAMA, 1997, NOTICE IS HEREBY GIVEN THAT SPLAWN CONSTRUCTION, INC. CONTRACTOR(S) HAVE COMPLETED EAST PINSON VALLEY RECREATION CENTER WATERPROOFING at 3000 JEFFERSON STATE PARKWAY, BIRMINGHAM, AL 35215 FOR THE CITY OF BIRMINGHAM AND HAVE MADE REQUEST FOR FINAL SETTLEMENT OF SAID CONTRACT, CONTRACTOR SPLAWN CONSTRUCTION, INC. BUSINESS ADDRESS 906 ALTON PARKWAY, BIRMINGHAM, AL 35210
BT3/19/2026
________________________________
SECTION 006519 ADVERTISEMENT FOR COMPLETION
LEGAL NOTICE
IN ACCORDANCE WITH SECTION 39-1 AS AMENDED BY H275 CODE OF ALABAMA, 1997, NOTICE IS HEREBY GIVEN THAT SPLAWN CONSTRUCTION, INC. CONTRACTOR(S) HAVE COMPLETED Birmingham Fire Stations 1, 12, & 25 Bay Heater Replacement
Fire Station 1: 1808 1st Avenue North, Birmingham, AL 35203
Fire Station 12: 6449 1st Avenue North, Birmingham, AL 35212
Fire Station 25: 3015 Wilson Road SW, Birmingham, AL 35211
FOR THE CITY OF BIRMINGHAM AND HAVE MADE REQUEST FOR FINAL SETTLEMENT OF SAID CONTRACT CONTRACTOR SPLAWN CONSTRUCTION, INC. BUSINESS ADDRESS 906 ALTON PARKWAY, BIRMINGHAM, AL 35210
BT3/19/2026
_________________________________
CIVIL SUMMONS
Court Case Number: 27-CV-2025-900279.00
In the Circuit Court of Dallas County, Alabama County, Alabama
Sherry Ann Suttles v Board of Thornton & Phoebe Smith c/o Arnold Sheppard
NOTICE TO: BOARD OF THORNTON & PHOEBE SMITH C/O Arnold SHEPPARD, PRES 2568 GATE POST CIRCLE BIRMINGHAM, AL 35214
THE COMPLAINT OR OTHER DOCUMENT ATTACHED TO THE SUMMONS IS IMPORTANT. AND YOU MUST TAKE IMMEDIATE ACTION TO PROTECT YOUR RIGHTS. YOU OR YOUR ATTORNEY IS REQUIRED TO FILE THE ORIGINAL OF YOUR WRITTEN ANSWER. EITHER ADMITTING OR DENYING EACH ALLEGATION IN THE COMPLAINT OR OTHER DOCUMENT. WITH THE CLERK OF THIS COURT. A COPY OF YOUR ANSWER MUST BE MAILED OR HAND DELIVERED TO YOU OR YOUR ATTORNEY, OR TO THE PLAINTIFF(S) OR ATTORNEY(S) OF PLAINTIFF(S). SHERRY ANN SUTTLES
WHOSE ADDRESSES ARE: P O BOX 228, SELMA, AL 36702
THIS ANSWER MUST BE MAILED OR DELIVERED WITHIN 30 DAYS AFTER THIS, AND THE COMPLAINT OR OTHER DOCUMENT WAS SERVED ON YOU, OR A JUDGMENT BY DEFAULT MAY BE RENDERED AGAINST YOU FOR THE MONEY OR OTHER THINGS DEMANDED IN THE COMPLAINT OR OTHER DOCUMENT.
BT3/19/2026
_________________________________
NOTICE TO BIDDERS
Sealed Bid Proposals will be received by the Environmental Services Department, Jefferson County, Alabama, online at QuestCDN (eBidDoc #10082719), until 2:00 P.M. local time on Thursday, April 16, 2026 and then publicly opened and read via virtual video conference using Microsoft Teams for the SANITARY SEWER SYSTEM – ASSET MANAGEMENT PROGRAM – CONTRACT NO. 2022 PS04 – WELLINGTON AND FOX HOLLIES PUMP STATION UPGRADES. Microsoft Teams can be accessed using a direct invitation link sent via email (request this link from Tad Powell, Hazen, and Sawyer, at email tpowell@hazenandsawyer.com).
The scope of work includes the construction of new 150 GPM and 290 GPM submersible type pump stations and associated appurtenances and site work, abandonment of existing pump station and sewer lines, rehabilitation of wet wells, and installation of natural gas driven suction lift backup pump, temporary flow control, and other appurtenant work.
Bidding Documents are on file for inspection, by appointment only, at the following location:
Jefferson County Environmental Services Department
716 Richard Arrington Jr. Boulevard North, Suite A-300
Birmingham, Alabama 35203
Contact for Appointment: Gabrielle Sinsky at (205) 568-5710
Complete sets of electronic Bidding Documents (Specifications and Drawings) are available at https://www.jeffcoes.org (navigate to “BIDS/CONTRACTS” to “NOTICE TO BIDDERS” to “Asset Management Program – Project Bid Information” for a listing of projects. Prior to downloading the Bidding Documents, Bidders will be required to set up a QuestCDN.com account and pay a $64.00 fee ($22.00 fee for download only). Hard copies of the Bidding Documents are the responsibility of the Bidders. Contact QuestCDN at 952-233-1632 or info@questcdn.com for assistance with navigating the website and digital project information.
Bids will only be accepted from pre-qualified contractors who are listed on the Plan Holders List, signifying that they have purchased a set of documents from the Engineer, and who attend the MANDATORY Pre-Bid Conference.
NO BID PROPOSAL SHALL BE ACCEPTED AFTER THE TIME STATED FOR RECEIVING BID PROPOSALS IN THIS NOTICE. A FORM CONTAINING THE CONTRACTOR’S NAME AND ADDRESS OF THE FIRM AND THE CONTRACTOR’S ALABAMA LICENSE NUMBER WITH THE DATE OF EXPIRATION IS REQUIRED WITH THE SUBMISSION OF THE BID. THESE REQUIREMENTS SHALL NOT BE WAIVED.
The Contractor is hereby advised that TIME IS OF THE ESSENCE on this project. The Contract Time for this project is three hundred (300) consecutive calendar days. The first 120 days will be an administrative period followed by a 180-day construction period from the effective date of the written Notice to Proceed to achieve Final Acceptance. If mutually agreed upon between the Owner and Contractor, the construction period may commence prior to the end of the administrative period. Upon such agreement the contract end date will be modified based on the date of termination of the administrative period. Liquidated damages will be assessed if this time limit is exceeded. The Contractor may apply for an extension of time in accordance with the provisions of the Contract; however, such an extension must be approved prior to the Contract Completion Date to avoid the imposition of liquidated damages.
The Contractor is hereby advised that a Pre-Bid Conference will be held via a virtual video conference on Wednesday, APRIL 1, 2026, at 2:00 p.m. This Pre-Bid Conference is MANDATORY for all contractors planning to submit a Bid Proposal on this project. The conference call will be held using Microsoft Teams and can be accessed using a direct invitation link sent via email (request this link from Tad Powell, Hazen, and Sawyer, at email tpowell@hazenandsawyer.com). If you are unable to join the call due to technical difficulties, call Tad Powell (Hazen and Sawyer) at 205-957-4151 or Gabrielle Sinksy at (205) 568-5710 for assistance.
Questions concerning meaning or intent of Bidding Documents shall be submitted to Tad Powell, PE, Senior Associate, Hazen, and Sawyer, at email tpowell@hazenandsawyer.com no later than 5:00 p.m. local time on April 8, 2026. All questions must be in writing on Bidder’s company’s letterhead.
THE ATTENTION OF ALL BIDDERS IS CALLED TO THE PROVISIONS OF THE STATE LAW GOVERNING GENERAL CONTRACTORS, AS SET FORTH IN ALABAMA CODE SECTIONS 34-8-1 THROUGH SECTION 34-8-28 (1975), AS AMENDED, CHAPTER 4, SECTION 65 TO 82 (INCLUSIVE) OF TITLE 46 OF THE CODE OF ALABAMA OF 1940, AS AMENDED; AND BIDDERS SHALL BE GOVERNED BY SAID LAW INSOFAR AS IT IS APPLICABLE. THE ABOVE MENTIONED PROVISIONS OF THE CODE MAKE IT ILLEGAL FOR THE OWNER TO CONSIDER A BID PROPOSAL FROM ANYONE WHO IS NOT PROPERLY LICENSED UNDER SUCH CODE PROVISIONS.
THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA CODE SECTION 39-2-14 (1975) AS AMENDED, REQUIRING A NONRESIDENT CONTRACTOR TO REGISTER WITH THE DEPARTMENT OF REVENUE PRIOR TO ENGAGING IN THE PERFORMANCE OF A CONTRACT IN THE STATE OF ALABAMA.
THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA CODE SECTION 39-3-5 (1975) AS AMENDED, REGARDING PREFERENCE TO RESIDENT CONTRACTORS.
THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA ACT 2016-312 AS AMENDED, REGARDING NOT ENGAGING IN THE BOYCOTT OF A PERSON OR ENTITY BASED IN OR DOING BUSINESS WITH A JURISDICTION WITH WHICH THIS STATE ENJOYS OPEN TRADE.
THIS PROJECT IS CLASSIFIED AS A CLASS “D1” SMALL, PRE-CAST PUMPING STATIONS & RELATED FACILITIES SEWER PROJECTS. ALL PROSPECTIVE BIDDERS MUST BE PRE-QUALIFIED WITH THE JEFFERSON COUNTY ENVIRONMENTAL SERVICES DEPARTMENT TO BID CLASS “D1” SMALL, PRE-CAST PUMPING STATIONS & RELATED FACILITIES SEWER PROJECTS IN ORDER TO BID ON THIS PROJECT. THE PROSPECTIVE BIDDER OR ITS SUBCONTRACTOR MUST ALSO BE PREQUALIFIED TO CONSTRUCT, AT A MINIMUM, CLASS “A” SEWER LINE PROJECTS. To pre-qualify with the department and to construct class “D1” SMALL, PRE-CAST PUMPING STATIONS & RELATED FACILITIES SEWER PROJECTS, each prospective bidder must furnish written evidence of competency and evidence of financial responsibility to the county.
ACCORDINGLY, THE COUNTY WILL NOT ACCEPT PRE-QUALIFICATIONS AFTER MARCH 27, 2026. BID PROPOSAL FORMS WILL NOT BE ISSUED TO PROSPECTIVE BIDDERS WHO DO NOT PRE-QUALIFY.
CONTRACTORS ARE ENCOURAGED TO CONTACT THE JEFFERSON COUNTY ENVIRONMENTAL SERVICES DEPARTMENT, 716 RICHARD ARRINGTON JR. BOULEVARD NORTH, SUITE A300, BIRMINGHAM, ALABAMA, (205) 325-5496 IN ADVANCE OF THE DEADLINE TO DETERMINE IF THE CONTRACTOR IS PRE-QUALIFIED TO CONSTRUCT CLASS “D1” SMALL, PRE-CAST PUMPING STATIONS & RELATED FACILITIES SEWER PROJECTS, OR FOR OTHER INFORMATION REGARDING THE REQUIREMENTS FOR PRE-QUALIFICATION.
David Denard
Director of Environmental Services
Jefferson County, Alabama
BT3/19/2026
_________________________________
LEGAL NOTICE
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that BCS,LLC has completed the Contract for Statewide (North Region) Energy Controls Modernization, Contract # AC-24-C-0041-S, located at various locations, Alabama, for the Armory Commission of Alabama, Owner, and have made request for final settlement of said Contract. All persons having any claim for labor, materials or otherwise in connection with this project should immediately notify the:
Armory Commission of Alabama,
P.O. Box 3711,
Montgomery, Alabama
36109-0711
BCS, LLC
3125 County Road 3328
Brundidge, AL 36010
BT3/19/2026
_________________________________
REQUEST FOR PROCUREMENT (RFP) No. FY 2025-002
FINANCIAL AUDIT SERVICES
DA TE ISSUED: MARCH 2, 2026
TYPE OF PROJECT: The Agency is seeking sealed bids from qualified licensed and insured entities to provide financial audit services. These services are a necessary supplement to the daily operation of the Agency. The successful bidder shall be a qualified professional firm or individuals of certified public accountants to provide auditing services of financial statements for the Fiscal Years 2026, and 2027, with the option of auditing its financial statements for each of the following four ( 4) subsequent fiscal years at the sole option of F AHA. These audits are to be performed in accordance with the specifications outlined in this solicitation.
CONTACT PERSON: Renae Garrett, Executive Administrative Assistant
PRE-PROPOSAL CONFERENCE: NIA
PROPOSAL QUESTION DEADLINE: Tuesday, March 17, 2026, 2:00 p.m. CST
AGENCY’S ANSWERS TO QUESTIONS ISSUED: Tuesday, March 24, 2026, by 2:00p.m. CST
SUBMISSION DEADLINE: Wednesday, April 1, 2026, by 2:00p.m.
SUBMITTAL ADDRESS: FAIRFIELD ALABAMA HOUSING AUTHORITY, 6704 Avenue D Fairfield, AL 35064
BT3/19/2026
_________________________________
INVITATION TO BID
The City of Birmingham will accept sealed bids for the project 5th Ave S at 32nd St S – Drainage Improvements; Project # ENG 2025-020. Bids will be received by the City Engineer in Suite 220 of City Hall, Birmingham, Alabama until Wednesday, April 8, 2026, at 2:00 pm (CST). Sealed bids will be time-stamped at the time of arrival. Bids will then be publicly opened and read in Suite 220 Conference Room beginning at 2:00 pm. It is the bidder’s responsibility to make sure that the bid is in the possession of the City Engineer on or before time set for opening. Bids received after this time will not be considered. Bids can be dropped into the bid box located in Room 220 City Hall, hand-delivered to the City Engineer in Room 220 of City Hall or brought to the bid opening.
This is a project to replace storm pipe along 5th Ave S from 32nd St to 33rd St along with other minor drainage repairs and improvements.
Approximate primary quantities:
36” RCP – 550 LF, 18” RCP – 100 LF, Inlets – 5 Each, Manholes – 3 Each, Roadway backfill – 500 CY, Roadway Patching
A MANDATORY PRE-BID CONFERENCE will be held on Wednesday, March 25, 2026, at 3:00 pm (CST) in Conference Room 220 City Hall.
Bid documents are open to public inspection at the Office of the City Engineer in the Department of Capital Projects — Suite 220 of City Hall, 710 20th Street North, Birmingham, AL 35203. Bid documents may be viewed and purchased through the City of Birmingham online plans room site at https://www.birminghamplanroom.com/ under the project name 40th St N Street Improvements. Any cost for reproduction shall be the responsibility of bidders. Prospective bidders are advised to check their source of bid documents frequently for any addenda to the bid documents. It is the bidder’s responsibility to bid on the correct set of bid documents.
Bids shall be accompanied by a cashier’s check drawn on an Alabama bank, or a bid bond executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama, in an amount equal to 5% of the bid (subject to maximum of $10,000) and payable to the City of Birmingham. Bid bonds of the three (3) lowest bidders will be held for a period of ninety (90) days unless bidders agree, in writing, to a longer period of time. No bid may be withdrawn after the scheduled closing time for the receipt of the bids for a period of ninety (90) days.
A performance bond equal to 100% of the contract amount and a payment bond equal to 100% of the contract amount will be required of the successful bidder during the award process. Said bonds shall be executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama.
Liability insurance certificates shall be required of the successful bidder during the award process, and such certificates shall list the City of Birmingham, its officials, agents, and employees as additional named insured.
Only bids submitted by General Contractors licensed in the State of Alabama in accordance with Alabama Code Chapter 8, Title 34 (inclusive) will be considered.
Bids shall be submitted in a sealed envelope marked “5th Ave S at 32nd St S – Drainage Improvements” on the outside of each envelope. Contractors shall also write on the outside of the sealed bid envelope his or her State of Alabama general contractor’s license number as well as the name of the company submitting the bid.
The sealed bid envelope shall contain the following documents: (1) the Form of Proposal, (2) Sales Tax Attachment form, (3) the Authorization to Execute form, (4) fully executed bid bond or certified check, (5) MBE/DBE Forms A, C, and D, (6) a copy of the contractor’s current State of Alabama General Contractor’s License, (7) a current City of Birmingham Business License, (8) E-verify documentation, (9) Transparency in City Government form, and (10) List of Subcontractors.
This project is subject to the requirements of the Birmingham Plan-Construction Industry Program, which is designed to encourage the utilization of Minority Business Enterprises and Disadvantaged Business Enterprises (“MBE/DBE”) in City of Birmingham construction projects. The program is administered by the Birmingham Construction Industry Authority (BCIA) which establishes a system of floating MBE/DBE goals which may differ from year to year and project to project. Overall, these goals shall not be less than the historical participation of MBE/DBE’s in construction projects of the City and its agencies.
Special attention is called to the requirement of all bidders to identify trades and activities for which it will solicit and accept bids from potential MBE/DBE subcontractors. Potential bidders are encouraged to contact the Birmingham Construction Industry Authority (BCIA) to request a list of potential subcontractors and submit the required MBE/DBE forms by contacting the Executive Director, Birmingham Construction Industry Authority at 601 37th Street South, Birmingham, AL, 35222; telephone (205) 324-6202 or info@bcia1.org.
As a matter of public policy, the City of Birmingham agrees to make opportunities available to the maximum extent possible, to actively include Historically Underutilized Business Enterprises (HUBE’s) such as architectural firms, engineering firms, investment banking firms, other professional consultant services providers, and construction contractors as part of business, economic and community revitalization programs.
The City of Birmingham reserves the right to reject any or all bids and to waive any informality in any bid.
Jesse Miller, PE
City Engineer
BT3/19/2026
_________________________________
NOTICE OF SELECTION OF PROJECT-BASED VOUCHERS (PBV) PROPOSAL
In accordance with 24 CFR 983.51(f), the Housing Authority of the Birmingham District hereby provides notice of the selection of PBV proposals to provide housing under the PBV program.
The selected PBV proposal are as follows:
|
Project Name
|
Applicant
|
Number of PBV Units
|
|
North Titusville area (5th Ave Holdings)
|
Navigate Housing
|
18
|
|
The Star
|
CR Endeavors
|
19
|
Inquiries to this notice or requests to review the application and selection information can be directed to Kozette Todd, Procurement Manager at ktodd@habd.net.
BT3/19/2026
_________________________________
LEGAL NOTICE
The Birmingham Airport Authority (“BAA” or “Authority”) is soliciting Statements for Qualifications and Project Proposals from qualified firms to perform Construction Administration for CCTV Installation at Birmingham-Shuttlesworth International Airport. Copies of the RFQ can be obtained by visiting the airport’s website at http://www.flybhm.com or via email request sent to eseoane@flybhm.com. There will be a non-mandatory pre-submittal meeting in the BAA terminal Meeting Room A on March 23, 2026, at 2:00PM and you must RSVP eseoane@flybhm.com by March 20, 2026. SOQ deadline is April 13th, 2026.
BT3/19/2026
_________________________________
CITY OF BIRMINGHAM, ALABAMA
PY 2026 ANNUAL ACTION PLAN USE OF FUNDS SUMMARY
PUBLIC REVIEW MEETING NOTICE
In accordance with 24 CFR Part 91, the City of Birmingham’s Community Development Department is hereby publishing its Notice of Public Hearing and Program Year PY 2026 Draft Annual Action Plan (AAP) for review & Comment for Use of Funds. This publication provides affected residents and stakeholders with an opportunity to hear the proposed plan and submit comments.
Please note: All proposed activity allocations are subject to proportional adjustment, either increased or decreased, based on the final funding amounts awarded to the City.
The Public Hearings will be:
- In Person April 8, 2026, at 4 PM. – 5 PM in the Birmingham City Hall – Council Chambers, 710 20th Street North, 3rd Floor, Birmingham, AL 35203
- Virtual Public Hearing April 9, 2026, at 9 AM.
Virtual meeting links will be posted at: https://www.birminghamal.gov/government/city-departments/community-development/community-development-block-grant
Public comments will be accepted April 10 – May 14, 2026, at 4:00 p.m. at:
Community Development
710 North 20th Street – 10th Floor Room 1000
Birmingham, AL 35203 OR via Email address: HousingAndCommunityInfo@birminghamal.gov
The PY 2026 Draft AAP will be available for public review at:
Community Development Department, 710 North 20th Street, Room 1000, Birmingham, AL 35203
Monday – Friday, 9 AM – 4 PM
OR Online at: www.birminghamal.gov/government/city-departments/community-development
Special Assistance: Persons needing accommodations, translated materials, or a draft copy of the report should contact the Community Development Department at housingandcommunityinfo@birminghamal.gov or (205) 254-2309.
| RECOMMENDED ANNUAL ACTION PLAN BUDGET | |
| July 1, 2026 – June 30, 2027 | |
| PY 2026 Community Development Block Grant | $ 5,733,710.00 |
| PY 2026 Anticipated Program Income: | $ 50,000.00 |
| CDBG Total: | $ 5,783,710.00 |
| PY 2026 HOME Grant: | $ 1,138,846.56 |
| PY 2026 Anticipated HOME Program Income: | $ 100,000.00 |
| HOME Total: | $ 1,238,846.56 |
| PY 2026 Emergency Shelter Grant (ESG): | $ 506,318.00 |
| PY 2026 HOPWA Grant: | $ 1,795,327.00 |
| TOTAL | $ 9,324,201.56 |
| PROJECT: COMMUNITY DEVELOPMENT BLOCK GRANT (CDBG) | $5,783,710.00 |
| PLANNING & ADMINISTRATION | $ 1,116,742.00 |
| ONE ROOF- PLANNING | $ $40,000.00 |
| PROJECT: REPAYMENTS OF SECTION 108 LOAN | $ 235,000.00 |
| ECONOMIC DEVELOPMENT | $ 725,000.00 |
| HOUSING REHABILITATION | $ 1,150,000.00 |
| HOUSING PROGRAM COST | $ 1,500,000.00 |
| ACQUISITION | $ 50,000.00 |
| PUBLIC SERVICES (15% cap) | $ 867,556.50 |
| PUBLIC FACILITIES & INFRASTRUCTURE | $ 89,411.50 |
| BROADBAND | $ 10,000.00 |
| HOME INVESTMENT PARTNERSHIP PROGRAM (HOME) | $ 1,238,846.56 |
| ADMINISTRATION- 10% | $ 123,884.65 |
| CHDO ACTIVITIES- 15% | $ 185,826.98 |
| Down Payment Assistance | $ 500,000.00 |
| Home Buyer/ Rental | $ 429,134.93 |
| PROJECT: EMERGENCY SOLUTIONS GRANT PROGRAM (ESG) | $ 506,318.00 |
| Street Outreach, Emergency Shelter, Essential Services
& Operations Maintenance |
$ 379,344.15 |
| HOMELESSNESS PREVENTION | $ 55,000.00 |
| RAPID RE-HOUSING | $ 34,000.00 |
| ADMINISTRATION (7.5%): | $ 37,973.85 |
| PROJECT: HOUSING OPPORTUNITIES FOR PERSONS WITH AIDS (HOPWA) | $ 1,795,327.00 |
| AIDS ALABAMA, INC. | |
| Rental Assistance/TBRA | $ 410,000.00 |
| Rental Assistance/STRMU | $ 76,301.80 |
| Supportive Services | $ 538,598.00 |
| Operating Costs | $ 520,894.50 |
| Resource Identification | $ 70,000.00 |
| Sponsor Administration (7%) | $ 125,672.89 |
| ADMINISTRATION (Grantee) (3%) | $ 53,859.81 |
| GRAND TOTAL | $ 9,324,201.56 |
BT3/19/2026
_________________________________
BID# 26-14-04(A) & (B)
NOTICE TO BIDDERS
Central Alabama Water will be accepting sealed bids for Lawn Maintenance-Western Filter Plant, BID# 26-14-04(A) and Shades Mountain Filter Plant, BID# 26-14-04(B).
The specifications may be examined and obtained in the Purchasing Department’s office at 3600 First Avenue North, Birmingham, AL 35222, or by emailing shayla.townsend@caw-al.gov , or on our website at www.caw-al.gov
Pre-Bid (MANDATORY) Site Visit Scheduled for both locations on:
- Monday, March 16, 2026 from 10:30am-11:30am for Lawn Maintenance-Western Filter Plant
- Monday, March 16, 2026 from 12:00pm-1:00pm for Lawn Maintenance-Shades Mountain Filter Plant where questions will be answered.
Prospective bidders should deliver or mail their sealed bids to 3600 1st Avenue North, Birmingham, Alabama 35222, directed to the attention of LyTonja Levert, Purchasing Manager, and marked in the lower left-hand corner of the envelope as follows: (“Bid for Lawn Maintenance-Western Filter Plant #26-14-04(A) and Shades Mountain Filter Plant, BID# 26-14-04(B) ”) Tuesday, March 24 , 2026, at 10:00 a.m.”
BT3/19/2026
_________________________________
Quitclaim Deed
STATE OF ALABAMA
COUNTY OF JEFFERSON
DATE: OCTOBER 24, 2025
KNOW ALL MEN BY THESE PRESENTS THAT:
For and in consideration of the sum of 21.33 troy ounces of silver [$35,000 cash equivalent], the receipt of which is hereby acknowledged, the undersigned Trustees Roderick Smith I Ezella Smith, of Roderick and Ezella Smith Family Trust/ (RES FAMILY TRUST), an Alabama Revocable Trust whose tax mailing address is PO BOX 610392, BIRMINGHAM, AL 35261, USA, (the “Grantor”), hereby remises, releases, grants, sells, and conveys, as well as quitclaim, unto Darren Washington, dated October 24, 2025, (the “Grantee”), all of the Grantor’s right, title, interest and claim in or to the following described real estate, situated in Jefferson County, Alabama: 4705 Terrace S, Birmingham, AL 35208
SUBD: CENTRAL PARK LD CO 29-7&8 SEC/TWN/RNG/MER: SEC 08 TWN 18S RNG 03W LOT·2 BLK 7 CENTRAL PARK LAND COMPANY’S FIRST SURVEY.
BT3/19/2026
_________________________________
LEGAL NOTICE
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, as amended, notice is hereby given that: Central Alabama Asphalt & Construction Co., LLC has completed the contract for the construction of Irondale 2025 Paving for the State of Alabama, and the County of Jefferson, and have made request for final settlement of said contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify:
Central Alabama Asphalt & Construction Co., LLC
3181 Fosters Ferry Road, Tuscaloosa, Alabama 35401
Office: (205) 349-0910
BT3/19/2026
_________________________________
IN THE CIRCUIT COURT OF JEFFERSON COUNTY, ALABAMA
QUINTEZ CHAPMAN v ARKIEMIA HOLLEY
CIVIL ACTION NO. 01-CV-2025-900674
DEFENDANT WARNING ORDER AS TO ARKIEMIA HOLLEY
To: Arkiemia Holley, Defendant: You are hereby notified that Quintez Chapman, whose attorney is Barry D. Burton, 1905 14th Avenue South, Birmingham, Alabama 35205, has filed a complaint against you, a copy of the complaint and summons shall be delivered to you or your attorney upon request. You are also notified that you must appear and defend by filing an Answer within thirty (30) days of the date of the first publication of this Warning Order; and in the event of your failure to do so, judgment by default may be entered against you for the relief demanded in the Complaint.
Jacqueline Anderson Smith
Circuit County Clerk
Jefferson County, Alabama
716 Richard Arrington, Jr. Blvd.
Birmingham, Alabama 35203
205-325-5355
BT3/19/2026
_________________________________
Invitation for General Contractor Services Bid
ADVERTISEMENT FOR BIDS Notice is hereby given that Jefferson State Community College will be accepting sealed bids for General Contractor Services for the Jefferson, Shelby-Hoover, St. Clair-Pell City & Chilton –Clanton Campuses.
JSCC Bid #26-006 for General Contractor Services will need to be delivered on Thursday, April 14, 2026, by 3:00 p.m. local time to Jefferson State Community College, 2601 Carson Road, George Wallace Hall, Room 115, in Birmingham, AL 35215.
A complete set of Bid Documents shall be available through the Jefferson State Community College Purchasing Office.
By Mail: Jefferson State Community College
Purchasing Coordinator
2601 Carson Road
GWH 100
Birmingham, AL 35215
Phone: 205-856-8020
Email: purchasing@jeffersonstate.edu
Bids must be sealed when received and submitted on Proposal Forms furnished in the Bid Documents or copies thereof. The preceding is an abbreviated advertisement. The complete advertisement may be obtained via the contact information or location listed above.
BT3/19/2026
_________________________________
PROBATE COURT OF JEFFERSON COUNTY
716 RICHARD ARRINGTON, JR. BLVD. N., BIRMINGHAM, ALABAMA 35203
YASHIBA GLENN BLANCHARD, JUDGE
CHIEF ELECTION OFFICIAL, JEFFERSON COUNTY
205-325-5203
March 13, 2026
LEGAL NOTICE
Pursuant to the provisions of Title 17, Chapter 9, Section 5 of the Code of Alabama, notice is hereby given that a Gubernatorial Primary Election will be held at polling places in Jefferson County, Alabama on Tuesday, May 19, 2026. The Polls will be open from 7:00 a.m. until 7:00 p.m. A public test of voting machines will be held from 8:30 a.m. to 9:30 a.m. on Tuesday, May 12, 2026, at the Jefferson County Operations Center located at 520 Medco Road, Birmingham, AL 35217.
Pursuant to the provisions of § 21-4-23, Code of Alabama (1975), notice is hereby given that:
- Instructions, printed in large type, will be conspicuously displayed at each voter registration site and polling place, sufficient to provide hearing impaired and seriously visually impaired individuals with adequate information as to how and where they may register and vote.
- Each polling place shall have an Express Voter Assist Terminal for use by individuals with disabilities who would otherwise be prevented from voting because of their inability to mark a paper ballot.
- Absentee ballots are available to any individual with a disability or elderly individual who, because of disability or age, is unable to go to their assigned polling place to vote on election day. The deadlines for requesting and submitting an absentee ballot are the same as for other persons seeking to vote by absentee ballot.
- Any handicapped or elderly individual who, because of handicap or age, requires assistance in casting a vote, may select a person of his or her choice to accompany such individual into the polling place to assist in the casting of the vote.
Further, § 17-9-13(a), Code of Alabama (1975) states, “Any person who wishes assistance in voting may receive assistance from any persons the voter chooses except the voter’s employer, an agent of the employer, or an office or agent of the voter’s union.”
BT3/19/2026
_________________________________
Abandoned Vehicle
Abandoned 1991 Alfa Romero Spider (vin ZARBB32G6M6003153) set for auction on 04/24/26. Contact 205-516-1092 for more info.
BT3/19/2026
_________________________________
PUBLIC AUCTION NOTICE
Abandoned 2013 Chevrolet Camaro 2SS (White/Black), VIN: 2G1FK1EJ2D9199682. Sale to satisfy possessory lien (AL Code §32-13-3) on April 20, 2026, at 7:00 AM. Location: 1629 18th St SW, Birmingham, AL 35211. Sold to highest bidder; bond may be req. per §32-8-36. Owner/lienholder may redeem via payment of charges prior to auction. Contact: Zara Mccarther (10AM–4PM).
BT3/19/2026
__________________________________
OBITUARY- SPACE
BT3/19/2026
_________________________________
PUPPIES FOR SALE
MALE AND FEMALE YORKIES READY TO GO FREE FOR ADOPTION IF INTERESTED WRITE ME ON silvanarcos01@gmail.com TO GET MORE DETAILS ON THE PUPPIES.
BT3/19/2026
_________________________________
| HOUSING AUTHORITY BIRMINGHAM DISTRICT NOTICE OF
INVITATION FOR BID (IFB) No. B26004 Vacant Unit Preparation |
|
| AGENCY CONTACT PERSON | Kozette Todd, Procurement Manager
Telephone: (205)521-0762 E-mail: ktodd@habd.net TDD/TTY: 800-548-2546 |
| HOW TO OBTAIN THE RFP DOCUMENTS ON THE EPROCUREMENT MARKETPLACE | 1. Access ha.internationaleprocurement.com (no “www”).
2. Click on the “Login” button in the upper left side. 3. Follow the listed directions. 4. If you have any problems in accessing or registering on the Marketplace, please call customer support at (866)526-9266. |
| PRE-BID CONFERENCE | March 10, 2026 3:00 PM CT |
| DEADLINE TO SUBMIT QUESTIONS | March 23, 2026, 3:00 PM CT |
| BID SUBMITTAL RETURN DEADLINE | March 30, 2026, 3:00 PM CT 1826 3rd
Avenue South, Birmingham, Al 35233 |
| [Section 3, Minority- and/or women-owned businesses are encouraged to respond] | |
BT3/19/2026
_________________________________
| HOUSING AUTHORITY BIRMINGHAM DISTRICT NOTICE OF INVITATION FOR BID
INVITATION FOR BID (IFB) No. B26005 Professional Moving Services |
|
| AGENCY CONTACT PERSON | Darryl Grayson, Procurement Analyst Telephone: (205)521-0611
E-mail: dgrayson@habd.net TDD/TTY: 800-548-2546 |
| HOW TO OBTAIN THE RFP DOCUMENTS ON THE EPROCUREMENT MARKETPLACE | 5. Access ha.internationaleprocurement.com (no “www”).
6. Click on the “Login” button in the upper left side. 7. Follow the listed directions. 8. If you have any problems in accessing or registering on the Marketplace, please call customer support at (866)526-9266. |
| PRE-BID CONFERENCE | Thursday March 12, 2026, 3:00 PM CT |
| DEADLINE TO SUBMIT QUESTIONS | Tuesday March 24, 2026, 3:00 PM CT |
| BID SUBMITTAL RETURN DEADLINE | Friday April 3, 2026, 3:00 PM CT
1826 3rd Avenue South, Birmingham, Al 35233 |
| [Section 3, Minority- and/or women-owned businesses are encouraged to respond] | |
BT3/19/2026
_________________________________
INVITATION FOR BIDS
PROJECT: Oak Ridge & Terrace Manor Bathroom Renovation
4462 Oak Ridge Circle – Brighton, Alabama 35020
Oak Ridge 4501 Little Drive – Bessemer, Alabama 35022
OWNER:
Jefferson County Housing Authority
Architect’s Project#: 25056
Sealed proposals for the above-referenced project will be received by the Jefferson County Housing Authority on Thursday, April 9, 2026 at 2:00 pm local time, in the Conference Room of the JCHA Main Office located at 3700 Industrial Parkway, Birmingham, AL 35217, at which time and place they will be publicly opened and read.
The Owner highly recommends all interested contractors attend a Pre-Bid Conference to be held Thursday, April 2, 2026 at 11:00 am local time at the
Terrace Manor Community Office located at 4501 Little Drive, Bessemer, AL 35022, to familiarize themselves with the project.
The project consists of the removal and replacement of interior bathroom finishes and plumbing Questions should be directed to Mr. Roman Gary with CCR Architecture & Interiors
CCR Architecture & Interiors 2920 First Avenue South Birmingham, Alabama 352433
205-324-8864 phone
roman@ccrarchitecture.co m email
The CONTRACT DOCUMENTS, including drawings and technical specifications, may
be examined at the following locations: www.jcha.com/procurement , Alabama Graphics, Dodge Data & Analytics, Associated General Contractors (iSqFt), and CMD Group.
Copies of the CONTRACT DOCUMENTS may be obtained from Alabama Graphics, algraphicsplanroom. com.
Bids must be submitted on proposal forms furnished in the specifications. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered.
Licensing required by local municipalities shall be obtained prior to the execution of the construction contract.
A cashier’s check or bid bond payable to Jeferson County Housing Authority in an amount not less than five (5) percent of the amount of the bid, but in no event more than
$10,000, must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.
The contract shall be awarded to the lowest responsible bidder in accordance with the rules, regulations, and policies of the Jeferson County Housing Authority and the U.S. Department of Housing and Urban Development. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interests of the Owner will thereby be promoted.
Contractors are required to comply with the requirements of Section 3 for new employment, training, and contracting opportunities found in Title 24, CRF 135.
Jefferson County Housing Authority
(Owner)
CCR Architecture & Interiors
BT3/19/2026
_________________________________
NOTICE TO BIDDERS
Sealed Bid Proposals will be received by the Environmental Services Department, Jefferson County, Alabama, online at QuestCDN (eBidDoc #10104485), until 2:00 P.M. local time on Wednesday, April 29, 2026, and then publicly opened and read via virtual video conference using Microsoft Teams for the SANITARY SEWER SYSTEM – ASSET MANAGEMENT PROGRAM – CONTRACT NO. 2025 AMP04 – 2025 SEWER REHABILITATION.
Microsoft Teams can be accessed using a direct invitation link sent via email (request this link from Tad Powell, Hazen, and Sawyer, at email tpowell@hazenandsawyer.com).
The scope of work includes the rehabilitation of approximately 70,706 linear feet of 8-inch through 12-inch sanitary sewer pipe with cured-in-place liner, approximately 146 service lateral connection saddles via excavation, 1,488 service lateral launch inspections, 29 vertical feet of manhole replacement, 108 vertical feet of manhole installation, 85 segmental replacements 8-inch thru 12-inch sanitary sewer pipe via excavation, asphalt paving, and restoration work.
Bidding Documents are on file for inspection, by appointment only, at the following location:
Jefferson County Environmental Services Department 716 Richard Arrington Jr. Boulevard North, Suite A-300 Birmingham, Alabama 35203
Contact for Appointment: Ron Thomas at (205) 215-1661
Complete sets of electronic Bidding Documents (Specifications and Drawings) are available at https://www.jeffcoes.org (navigate to “BIDS/CONTRACTS” to “NOTICE TO BIDDERS” to “Asset Management Program – Project Bid Information” for a listing of projects. Prior to downloading the Bidding Documents, Bidders will be required to set up a QuestCDN.com account and pay a $64.00 fee ($22.00 fee for download only). Hard copies of the Bidding Documents are the responsibility of the Bidders. Contact QuestCDN at 952-233-1632 or info@questcdn.com for assistance with navigating the website and digital project information.
Bids will only be accepted from pre-qualified contractors who are listed on the Plan Holders List, signifying that they have purchased a set of documents from the Engineer, and who attend the MANDATORY Pre-Bid Conference.
NO BID PROPOSAL SHALL BE ACCEPTED AFTER THE TIME STATED FOR RECEIVING BID PROPOSALS IN THIS NOTICE. A FORM CONTAINING THE CONTRACTOR’S NAME AND ADDRESS OF THE FIRM AND THE CONTRACTOR’S ALABAMA LICENSE NUMBER WITH THE DATE OF EXPIRATION IS REQUIRED WITH THE SUBMISSION OF THE BID. THESE REQUIREMENTS SHALL NOT BE WAIVED.
The Contractor is hereby advised that TIME IS OF THE ESSENCE on this project. The Contract Time for this project is four hundred fifty (450) consecutive calendar days from the effective date of the written Notice to Proceed to achieve Final Acceptance. Liquidated damages will be assessed
if this time limit is exceeded. The Contractor may apply for an extension of time in accordance with the provisions of the Contract; however, such an extension must be approved prior to the Contract Completion Date to avoid the imposition of liquidated damages.
The Contractor is hereby advised that a Pre-Bid Conference will be held via a virtual video conference on Thursday, April 16, 2026, at 10:00 a.m. This Pre-Bid Conference is MANDATORY for all contractors planning to submit a Bid Proposal on this project. The conference call will be held using Microsoft Teams and can be accessed using a direct invitation link sent via email (request this link from Tad Powell, Hazen and Sawyer, at email tpowell@hazenandsawyer.com). If you are unable to join the call due to technical difficulties, call Tad Powell (Hazen and Sawyer) at 205-957-4151 or Ron Thomas (Jefferson County) at
(205) 215-1661 for assistance.
Questions concerning meaning or intent of Bidding Documents shall be submitted to Tad Powell, PE, Senior Associate, Hazen and Sawyer, at email tpowell@hazenandsawyer.com no later than 5:00 p.m. local time on April 22, 2026. All questions must be in writing on Bidder’s company’s letterhead.
THE ATTENTION OF ALL BIDDERS IS CALLED TO THE PROVISIONS OF THE STATE LAW GOVERNING GENERAL CONTRACTORS, AS SET FORTH IN ALABAMA CODE SECTIONS 34-8-1 THROUGH SECTION 34-8-28 (1975), AS AMENDED, CHAPTER 4, SECTION 65 TO 82 (INCLUSIVE) OF TITLE 46 OF THE CODE OF ALABAMA OF 1940, AS AMENDED; AND BIDDERS SHALL BE GOVERNED BY SAID LAW INSOFAR AS IT IS APPLICABLE. THE ABOVE-MENTIONED PROVISIONS OF THE CODE MAKE IT ILLEGAL FOR THE OWNER TO CONSIDER A BID PROPOSAL FROM ANYONE WHO IS NOT PROPERLY LICENSED UNDER SUCH CODE PROVISIONS.
THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA CODE SECTION 39-2-14 (1975) AS AMENDED, REQUIRING A NONRESIDENT CONTRACTOR TO REGISTER WITH THE DEPARTMENT OF REVENUE PRIOR TO ENGAGING IN THE PERFORMANCE OF A CONTRACT IN THE STATE OF ALABAMA.
THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA CODE SECTION 39-3-5 (1975) AS AMENDED, REGARDING PREFERENCE TO RESIDENT CONTRACTORS.
THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA ACT 2016-312 AS AMENDED, REGARDING NOT ENGAGING IN THE BOYCOTT OF A PERSON OR ENTITY BASED IN OR DOING BUSINESS WITH A JURISDICTION WITH WHICH THIS STATE ENJOYS OPEN TRADE.
THE EXCAVATION PORTION OF THIS PROJECT IS CLASSIFIED AS A CLASS “A” (8” thru 12” Diameter)” SEWER LINE PROJECT. ALL PROSPECTIVE BIDDERS MUST BE PRE-QUALIFIED WITH THE JEFFERSON COUNTY ENVIRONMENTAL SERVICES DEPARTMENT TO EITHER BID CLASS “A” SEWER LINE PROJECTS OR CURED-IN-PLACE PROJECTS IN ORDER TO BID ON THIS PROJECT. TO PRE-QUALIFY WITH THE DEPARTMENT AND TO CONSTRUCT CLASS “A” SEWER LINE PROJECTS OR CURED-
IN-PLACE PROJECTS, EACH PROSPECTIVE BIDDER MUST FURNISH WRITTEN EVIDENCE OF COMPETENCY AND EVIDENCE OF FINANCIAL RESPONSIBILITY TO THE COUNTY.
ACCORDINGLY, THE COUNTY WILL NOT ACCEPT PRE-QUALIFICATION APPLICATIONS AFTER April 10, 2026. BID PROPOSAL FORMS WILL NOT BE ISSUED TO PROSPECTIVE BIDDERS WHO DO NOT PRE-QUALIFY.
|
CONTRACTORS ARE ENCOURAGED TO CONTACT THE JEFFERSON COUNTY ENVIRONMENTAL SERVICES DEPARTMENT, 716 RICHARD ARRINGTON JR. BOULEVARD NORTH, SUITE A300, BIRMINGHAM, ALABAMA, (205) 325-5496 IN ADVANCE OF THE DEADLINE TO DETERMINE IF THE CONTRACTOR IS PRE-QUALIFIED TO CONSTRUCT CLASS “A” SEWER LINE PROJECTS OR CURED-IN-PLACE PROJECTS, OR FOR OTHER INFORMATION REGARDING THE REQUIREMENTS FOR PRE-QUALIFICATION.
BT3/19/2026
_________________________________
INVITATION TO BID
The City of Birmingham will accept sealed bids for 2026 Citywide Sidewalk Repairs Project # ENG 2026-003. Bids will be received by the City Engineer in Suite 220 of City Hall, Birmingham, Alabama until Wednesday, April 15, 2026, by 2:00 p.m. Sealed bids will be time-stamped at the time of arrival. Bids will then be publicly opened and read in Suite 220 Conference Room beginning at 2:00 pm. It is the bidder’s responsibility to make sure that the bid is in the possession of the City Engineer on or before time set for opening. Bids received after this time will not be considered. Bids can be dropped into the bid box located in Room 220 City Hall, hand-delivered to the City Engineer in Room 220 of City Hall or brought to the bid opening.
This is a sidewalk repairs project throughout each of the 9 districts throughout the city. Scope of work includes, but is not limited to replacement of sidewalks, concrete driveway replacement, brick paver rehab, curb & gutter, sidewalk grinding, ADA ramps, tree removal, and groundcover plantings. The primary items of work are approximately: 4” Concrete Sidewalks (2,850 SY), 6” Concrete Paving (500 SY), 18” Concrete Curb & Gutter (250 LF), Tree Removal (97 EA), and other items relating to repair of sidewalks.
A MANDATORY PRE-BID CONFERENCE will be held on Wednesday, April 1, 2026, at 2:00 pm (CST) in Conference Room 220 City Hall.
Bid documents are open to public inspection at the Office of the City Engineer in the Department of Capital Projects — Suite 220 of City Hall, 710 20th Street North, Birmingham, AL 35203. Bid documents may be viewed and purchased through the City of Birmingham online plan room site at https://www.birminghamplanroom.com/ under the above project name. Any cost for reproduction shall be the responsibility of bidders. Prospective bidders are advised to check their source of bid documents frequently for any addenda to the bid documents. It is the bidder’s responsibility to bid on the correct set of bid documents.
Bids shall be accompanied by a cashier’s check drawn on an Alabama bank, or a bid bond executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama, in an amount equal to 5% of the bid (subject to maximum of $10,000) and payable to the City of Birmingham. Bid bonds of the three (3) lowest bidders will be held for a period of ninety (90) days unless bidders agree, in writing, to a longer period of time. No bid may be withdrawn after the scheduled closing time for the receipt of the bids for a period of ninety (90) days.
A performance bond equal to 100% of the contract amount and a payment bond equal to 100% of the contract amount will be required of the successful bidder during the award process. Said bonds shall be executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama.
Liability insurance certificates shall be required of the successful bidder during the award process, and such certificates shall list the City of Birmingham, its officials, agents, and employees as additional named insured.
Only bids submitted by General Contractors licensed in the State of Alabama in accordance with Alabama Code Chapter 8, Title 34 (inclusive) will be considered.
Bids shall be submitted in a sealed envelope marked “2026 Citywide Sidewalk Repairs” on the outside of each envelope. Contractors shall also write on the outside of the sealed bid envelope his or her State of Alabama general contractor’s license number as well as the name of the company submitting the bid.
The sealed bid envelope shall contain the following documents: (1) the Form of Proposal, (2) Sales Tax Attachment, (3) the Authorization to Execute the Form of Proposal, (4) fully executed bid bond or certified check, (5) MBE/DBE Forms A, C, and D, (6) a copy of the contractor’s State of Alabama General Contractor’s License, (7) a current City of Birmingham Business License, (8) E-verify documentation, (9) list of subcontractors, and (10) Transparency in City Government form.
This project is subject to the requirements of the Birmingham Plan-Construction Industry Program, which is designed to encourage the utilization of Minority Business Enterprises and Disadvantaged Business Enterprises (“MBE/DBE”) in City of Birmingham construction projects. The program is administered by the Birmingham Construction Industry Authority (BCIA) which establishes a system of floating MBE/DBE goals which may differ from year to year and project to project. Overall, these goals shall not be less than the historical participation of MBE/DBE’s in construction projects of the City and its agencies.
Special attention is called to the requirement of all bidders to identify trades and activities for which it will solicit and accept bids from potential MBE/DBE subcontractors. Potential bidders are encouraged to contact the Birmingham Construction Industry Authority (BCIA) to request a list of potential subcontractors and submit the required MBE/DBE forms by contacting the Executive Director, Birmingham Construction Industry Authority at 601 37th Street South, Birmingham, AL, 35222; telephone (205) 324-6202 or info@bcia1.org.
As a matter of public policy, the City of Birmingham agrees to make opportunities available to the maximum extent possible, to actively include Historically Underutilized Business Enterprises (HUBE’s) such as architectural firms, engineering firms, investment banking firms, other professional consultant services providers, and construction contractors as part of business, economic and community revitalization programs.
The City of Birmingham reserves the right to reject and or all bids and to waive any informality in any bid.
Jesse Miller, PE City Engineer
BT3/19/2026
_________________________________
